HomeMy WebLinkAboutTONY PEREIRA - CONTRACT DocuSign Envelope ID:93D4BC30-6A6B-4B4C-A5B5-58026D55458A THIS IS A COPY
The Authoritative Copy of this record is held at na2.docusign.net
momentum
SOLAR
SOLAR ELECTRIC INSTALLATION CONTRACT
Tony Pereira
Customer Name
409 Northeast Oleander Avenue Port St. Lucie, FL 34952
Service Address City,State,Zip
(772) 446-5444 email@email.com
Phone Email Address
Florida Power & Light Co
Electric Utility Company
Hanwha Q CELLS Enphase Energy
10.44 kW Q.PEAK DUO BLK-G10+ 360 IQ7PLUS-72-2-US 46, 29
System Size' Solar Module Make/Type Inverter Make/Type 1111111116,19 Module Count
Battery Count Battery Make/Type Cost of Battery
Payment Schedule and Third-party Financing: Your payments will become due as indicated below. The "Total Amount
Payable to Momentum Solar" shown below reflects only the amount we charge for the PV System (as defined below) and
installation, not including any applicable sales tax. If you choose to obtain financing from a third-party finance company, your
payment schedule and total amount owed will be set out in your agreement with the third-party finance company and may
include finance charges. You should read that agreement carefully to understand your repayment obligations. We are not your
lender. The terms of any financing you obtain from a third party, including the amount and timing of your payments and any
finance charges imposed, are solely determined by your third-party finance company. We are not affiliated with any third-party
finance company.
TOTAL AMOUNT PAYABLE TO MOMENTUM SOLAR: $39,672.00 (PLUS ANY APPLICABLE SALES TAX)
FINANCED BY DIVIDEND FINANCE
iSCHEDULED PAYMENT—'
Refer to your agreement with Dividend Finance for a description of your payment obligations, including your
payment schedule and total of payments (including any finance charges).
TOTAL AMOUNT PAYABLE TO MOMENTUM SOLAR: $39,672.00
Optional Down Payment: $0.00
Upfront Rebate (if applicable): $0.00
Total Loan Amount: $39,672.00
Document.24 FL Page 1 of 10
DocuSign Envelope ID:93D4BC30-6A6B-4B4C-A5B5-58026D55458A THIS IS A COPY
The Authoritative Copy of this record is held at na2.docusign.net
momentum
SOLAR
You acknowledge that, regardless of whether you obtain financing from a third party, we require payment in full
upon completion of the installation (and required inspections) and that we are not extending credit to you in
connection with this transaction.
ACCORDING TO FLORIDA'S CONSTRUCTION LIEN LAW (SECTIONS 713.001-713.37, FLORIDA
STATUTES), THOSE WHO WORK ON YOUR PROPERTY OR PROVIDE MATERIALS AND SERVICES
AND ARE NOT PAID IN FULL HAVE A RIGHT TO ENFORCE THEIR CLAIM FOR PAYMENT AGAINST
YOUR PROPERTY. THIS CLAIM IS KNOWN AS A CONSTRUCTION LIEN. IF YOUR CONTRACTOR
OR A SUBCONTRACTOR FAILS TO PAY SUBCONTRACTORS, SUB-SUBCONTRACTORS, OR
MATERIAL SUPPLIERS, THOSE PEOPLE WHO ARE OWED MONEY MAY LOOK TO YOUR
PROPERTY FOR PAYMENT, EVEN IF YOU HAVE ALREADY PAID YOUR CONTRACTOR IN FULL.
IF YOU FAIL TO PAY YOUR CONTRACTOR, YOUR CONTRACTOR MAY ALSO HAVE A LIEN ON
YOUR PROPERTY. THIS MEANS IF A LIEN IS FILED YOUR PROPERTY COULD BE SOLD AGAINST
YOUR WILL TO PAY FOR LABOR, MATERIALS, OR OTHER SERVICES THAT YOUR CONTRACTOR
OR A SUBCONTRACTOR MAY HAVE FAILED TO PAY. TO PROTECT YOURSELF, YOU SHOULD
STIPULATE IN THIS CONTRACT THAT BEFORE ANY PAYMENT IS MAD.-, YOUR CONTRACTOR IS
REQUIRED TO PROVIDE YOU WITH A WRITTEN RELEASE OF LIEN FROM ANY PERSON OR
COMPANY THAT HAS PROVIDED TO YOU A "NOTICE TO OWNER." FLORIDA'S CONSTRUCTION
LIEN LAW IS COMPLEX, AND IT IS RECOMMENDED THAT YOU CONSULT AN ATTORNEY.
Ida
Pro Custom Solar LLC d/b/a Momentum Solar is a certified solar contractor(Cert.#CVC57036)with the Department
of Business Professional Regulation.
General Terms and Conditions
Definitions: In this agreement, the terms "customer", "owner", and "you" refer to the customer identified
above, and the terms "contractor", "us" and "we" refer to Pro Custom Solar LLC d/b/a Momentum Solar
and its employees, agents and subcontractors, as applicable. The term "agreement" or"contract" refers to
this agreement between you and us and any change orders signed by you and us. "PV System" means
the solar panels and related parts and the system of solar energy generation described above.
Scope of Work: We agree to sell and install the PV System on your real property. We will not provide, or
arrange for, arch itectu ral/eng i i leering services or structural changes to dwellings or buildings unless we
expreF-iy agree to do so in a separate writing signed by us. We have the right to determine the method,
details, and means of performing the work. We will obtain the necessary building and electrical permits
and ensure code compliance. You agree to cooperate with us to obtain these permits and meet code
compliance. You are solely responsible for obtaining, at your own cost and expense, any and all zoning
variances required by any municipality or local governing body. We will not obtain a zoning variance for
you unless we expressly agree to do so in a separate writing signed by us.
Change Orders: Any change to the work or the installation schedule that you or we request will be set out
in a written change order signed by both you and us. You agree that a change order may result in a
change to the terms of the agreement between you and us, including but not limited to, the contract price
and the anticipated installation schedule. If you request, in writing, a change to the scope or performance
of the services provided under this agreement, then we will provide you with a written change order for
your approval within a reasonable time after such written request. You agree that we may issue a change
order if a Force Majeure Event (as defined below) occurs that changes or impairs our ability to perform
under the current terms and conditions of this agreement. All change orders, including a change order
resulting from a Force Majeure Event, must be approved in writing by you within a reasonable time after
receipt, and you agree not to unreasonably withhold your approval of any change order.
Time Period: We anticipate beginning work under this agreement within fourteen (14) days after we
receive all required paperwork from the applicable state, utility, and municipality. We anticipate that we
Document.24 FL Page 2 of 10
DocuSign Envelope ID:93D4BC30-6A6B-4B4C-A5B5-58026D55458A THIS IS A COPY
The Authoritative Copy of this record is held at na2.docusign.net
momentum
SOLAR
will complete the work within thirty (30) days after we begin. This is our best estimate and is subject to
change according to various factors outside of our control. We are not responsible for delays resulting
from any Force Majeure Event (as defined below).
Force Majeure: We will not be liable to the you for any failure or delay in performance under this
agreement caused by events beyond our control including, without limitation: negligence or delay by any
governmental entity or utility company; your noncompliance with this agreement; your failure to furnish
necessary information or furnishing of incorrect information; legal encumbrances on your property; your
property's non-conformance with building codes or zoning requirements; your credit rating or financing
arrangements; acts of God, nature, government or any third parties; war or acts of terrorism; labor strife
or disputes; shortages of labor, fuel, raw materials or equipment; technical failures; accidents; sabotage;
failure or delays in transportation or communication; failures or substitutions of equipment; or hidden or
unforeseen physical or hazardous conditions, including but not limited to, environmental hazards such as
mold, asbestos, and lead paint (each, a "Force Majeure Event").
Your Responsibilities: You agree to pay us for merchandise delivery and/or installation of the PV System
according to the terms and conditions of this agreement. If your service address is subject to any
easements, covenants or other legal encumbrances that could affect the Installation, you agree to notify
us in writing, including by electronic mail or by certified mail, within five (5) business days of your becoming
aware of the encumbrance or prior to our beginning work, whichever is earlier. You agree to ensure that
work areas are free of preexisting hazards, including, but not limited to unsafe physical conditions or
environmental hazards and building/zoning code violations. You agree to allow us access to work areas
during work hours. If you have a security system, you agree to ensure that it does not interfere with
installation. You agree not to allow unattended minors at the service address while we are performing the
installation. You agree to control pets and keep them away from work areas. You agree that, if anyone
under your control interferes with or delays installation, you may be subject to transportation and/or storage
charges or other resulting charges.
Payments: All payments must be made in cash, by credit card, or by check(s) made payable to
"Momentum Solar" as specified in this agreement. Any payments you owe under your agreement with the
third-party finance company must be made in accordance with the terms of your agreement with them.
Failure to Pay: You will be in breach of this agreement if you fail to make any scheduled payment on time,
in full, and otherwise in accordance with this agreement. If we have not received the full amount of any
scheduled payment within ten days after the scheduled due date, you will incur a late fee equal to one
percent (1%) of the unpaid amount due. If the installation is not completed when the breach occurs, we
reserve the right to suspend all work until all past-due amounts have been paid in full. If the PV System
is in operation when the breach occurs, we reserve the right to remotely shut off the PV System until all
past-due amounts have been paid in full. Subject to applicable law, we may also pursue amounts you owe
us through legal action, which may include perfecting or enforcing a lien against your property or the PV
System. If we take legal action to enforce this agreement, you agree, to the maximum extent permitted
by applicable law, to pay reasonable attorney's fees and costs we incur before and after judgment and
any other costs permitted under applicable law. If you fail to pay your third-party finance company pursuant
to the terms of your agreement with them, you may be subject to any of the terms and remedies set forth
in that agreement. Please consult that agreement to determine your liability and rights regarding the third-
party finance company.
Inspection of System: You agree to allow us, our designees, and any state or local governmental
authority or utility company to inspect the PV System at the service address.
Cancellation by Customer: If you cancel this agreement at any time after the cancellation period
described in this agreement or otherwise prevent us from completing the installation, you agree to
Document.24 FL Page 3 of 10
DocuSign Envelope ID:93D4BC30-6A6B-4B4C-A5B5-58026D55458A THIS IS A COPY
The Authoritative Copy of this record is held at na2.docusign.net
momentum
SOLAR
reimburse us in full for the cost of materials, labor, and services provided up to the date and time of
cancellation.
Termination by Momentum: Prior to beginning design and permitting work, we will perform a physical
assessment of the installation site, including suitability of the existing electrical panel and wiring, roof
condition and shading of the intended location of the PV System to verify the suitability of the site for the
PV System. If we determine that existing site conditions will not allow for installation of a PV System as
described at the top of page 1, we may terminate this agreement if you and we are unable to agree to
modifications needed to provide for additional work needed to make the site suitable for the PV System.
If we do so terminate this agreement, we will refund your initial deposit in full. We may also terminate this
agreement after completion of our site assessment without further obligation if either (a) you breach this
agreement, or (b) we discover or become aware of: (i) previously undisclosed legal encumbrances or
easements affecting the service address, (ii) building/zoning code violations at the service address, or (iii)
hidden or unforeseen hazardous conditions such as the presence of mold, asbestos, lead paint, or any
other conditions not disclosed to us. 0 N
Component Manufacturer's Warranty: The manufacturers of certain of the PV System major
components warrant their components against certain defects. We have provided you with copies of all
manufacturer's warranties which govern your rights to seek a )medy from the respective manufacturer
with respect to covered defects. ,
Limited Warranty: You agree to contact us in writing, including by electronic wail or by certified mail, with
any problems or issues with the installation as soon as possible, but in any event within thirty (30) days
from the date you become aware of such problem. We will take reasonable measures to remedy or
otherwise resolve the problem within thirty (30) days after we receive your notice. You agree and
acknowledge that our limited warranty covers the installation only for a period of ten years. The limited
warranty does not apply if: (1) you fail to notify us of the problem within thirty (30) days, or (2) it is
reasonably determined, upon inspection, that any of the following conditions caused the need for service:
(a) damage resulting from accidents, acts of God, alterations or misuse; (b) your failure to properly follow
the operating instructions; c)) damage caused by animals; (d) alterations to your premises; or (e)
alterations to the PV Syste ade at your request, or made necessary by a change to your premises,
damage to your premises; or any other cause beyond our control. The PV System includes a monitoring
platform that allows us to remotely access performance information for the purpose of assessing the
sourc( )f performance issues that need to be remediated. Additionally, we warrant that any penetrations
of your roof used in the installation will not leak for a period of five (5) years. The limited roof penetrations
warranty does not apply if: (1) you fail to notify us of the problem within thirty (30) days, or (2) it is
reasonably determined, upon inspection, that any of the following conditions caused the need for service:
(a) damage res Alting from accidents, acts of God, alterations or misuse, (b) damage caused by animals;
(c) alterations or damage to your premises; or (d) any other cause beyond our control.
NO OTHER WARRANTIES: THE "LIMITED WARRANTY" RELATING TO OUR INSTALLATION OF THE
PV SYSTEM OR "COMPONENT MANUFACTURER'S WARRANTY" RELATING TO THE VARIOUS
COMPONENTS OF THE PV SYSTEM PROVIDED BY THE APPLICABLE MANUFACTURER, ARE THE
WARRANTIES PROVIDED UNDER THIS AGREEMENT. WE MAKE NO GUARANTEE OR WARRANTY
OF ANY KIND THAT EXTENDS BEYOND THE FACE OF THIS AGREEMENT, INCLUDING ANY
IMPLIED WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE WITH
RESPECT TO THE SERVICE PERFORMED OR THE SYSTEMS PROVIDED UNDER THIS
AGREEMENT.
LIMITATION OF DAMAGES: TO THE MAXIMUM EXTENT PERMITTED BY LAW, YOU AGREE TO
RELEASE US FROM ALL LIABILITY TO YOU OR ANY OTHER PERSON FOR ANY INCIDENTAL,
Document.24 FL Page 4 of 10
DocuSign Envelope ID:93D4BC30-6A6B-4B4C-A5B5-58026D55458A THIS IS A COPY
The Authoritative Copy of this record is held at na2.docusign.net
momentum
SOLAR
CONSEQUENTIAL OR PUNITIVE DAMAGES EXCEPT TO THE EXTENT SUCH DAMAGES ARE
CAUSED BY OUR GROSS NEGLIGENCE OR WILLFUL MISCONDUCT.
Binding Nature: This agreement shall bind and inure to the benefit of the respective heirs, personal
representatives, successors, and permitted assigns of each party.
Entirety of Contract; Modification; Waiver: This agreement constitutes the complete agreement
between you and us concerning the subject matter of this agreement and supersedes and cancels any
and all prior communications, representations, and agreements between you and us, whether written or
oral, with respect to the subject matter of this agreement. This agreement may not be amended or
modified unless in writing and executed by you and us. The rights and remedies of both parties under this
agreement are cumulative and not alternative. No waiver of any breach or failure to enforce or insist upon
performance any of the provisions of this agreement by either party at any time will in any way affect, limit
or waive such party's right to enforce and compel strict compliance with every provision of this agreement.
Severability: The invalidity or unenforceability of any provision of this agreement shall not affect the
validity or enforceability of any other provisions of this agreement, which shall remain in full force and
effect.
Assignment: Neither party may assign, transfer or delegate any or all of its rights or obligations under
this agreement, without the prior written consent of the other party, which consent shall not be
unreasonably withheld or delayed; provided, however, that (a) the contractor may assign this agreement
to any of its affiliates or to a successor of all or substantially all of the contractor's assets through merger,
reorganization, consolidation or acquisition and (b) such consent is not required for an assignment
(absolute, collateral or otherwise), pledge of, or grant of a security interest in, a right to payment under this
agreement by either party.
Dispute Resolution: In the "ofaspute, both you and we have the right to have the dispute resolved
in a court of law. In this dispute resolution provision, you and we are agreeing to limit that right. If you
have any dispute with us or if we have any dispute with you, then both you and we must seek resolution
of the dispute in either arbitration or small claims court. If your dispute cannot be resolved in small claims
court for any reason, then you must seek resolution of your dispute in arbitration. The arbitration hearing
will be held before a nationally recognized provider of arbitration services at a location of your choice within
your home state. The rules of the arbitration provider will apply. This dispute resolution agreement does
not alter any substantive rights that you may have understate or federal law. By signing below, you agree
to comply with this dispute resolution provision, which describes both your and our only procedure for
resolving any dispute. Only the arbitrator, not any federal, state, or local court or agency, has the authority
to interpret this provision or determine its applicability or enforceability. If any provision of this dispute
resolution provision is found to be unenforceable for any reason, such provision will be severed and the
remainder of this dispute resolution provision will continue in full force and effect. You understand and
accept that arbitration awards are subject to challenge only in limited circumstances.
Document.24 FL Page 5 of 10
DocuSign Envelope ID:93D4BC30-6A6B-4B4C-A5B5-58026D55458A THIS IS A COPY
The Authoritative Copy of this record is held at na2.docusign.net
momentum
SOLAR
Class Action Waiver: ARBITRATION MUST BE ON AN INDIVIDUAL BASIS. AS A RESULT, NEITHER
YOU NOR MOMENTUM MAY JOIN OR CONSOLIDATE CLAIMS IN ARBITRATION BY OR AGAINST
OTHER "CUSTOMERS", OR LITIGATE IN COURT OR ARBITRATE ANY CLAIMS AS A
REPRESENTATIVE OR MEMBER OF A CLASS OR IN A PRIVATE ATTORNEY GENERAL CAPACITY.
By initialing here, you agree to the terms of this paragraph: oS
Customer Initials:
Transfer of Title: The title of the equipment will pass to you upon the delivery of the equipment to your
property, or any storage facility you designate. Until the equipment has been delivered and signed for by
you or your agent, we retain the title for the equipment.
Governing Law: This agreement shall be governed by and construed in all respects in accordance with
the laws of the State of Florida as they apply to a contract entered into and performed in that state.
Taxes: You acknowledge and understand that you are responsible for any and all taxes at arise under
this agreement, including, but not limited to, sales and use taxes. You agree to execute any certificate
or other applicable documents relating to sales or use tax exemptions to ensure that you or we, as
applicable, may claim exemption from paying or collecting any sales or use tax that arises under this
agreement. You agree to pay all applicable sales or use taxes if such taxes are determined to be due at
any time before or after the termination nr expiration of this agreement. Momentum Solar and its
affiliates do not provide tax, legal or accounting advice. Any discussions between you and your sales
representative regarding federal, state or local tax incentives or rebates ("Tax Incentives") has been for
informational purposes only, and is not intended to provide, and should not be relied on for, tax, legal or
accounting advice. Momentum Solar makes no representations, warranties, or assurances as to the
accuracy, currency or completeness of the content of your discussion regarding Tax Incentives. You
should consult your own tax, legal and accounting advisors regarding the applicability to you of any Tax
Incentivc. .
FLORIDA HOMEOWNERS' CONSTRUCTION RECOVERY FUND. PAYMENT, UP TO A LIMITED
AMOUNT, MAY BE AVAILABLE FROM THE FLORIDA HOMEOWNERS' CONSTRUCTION
RECOVERY FUND IF YOU LOSE MONEY ON A PROJECT PERFORMED UNDER CONTRACT,
WHERE THE LOSS RESULTS FROM SPECIFIED VIOLATIONS OF FLORIDA LAW BY A LICENSED
CONTRACTOR. FOR INFORMATION ABOUT THE RECOVERY FUND AND FILING A CLAIM,
CONTACT THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD AT THE FOLLOWING
TELEPHONE NUMBER AND ADDRESS: DEPARTMENT OF BUSINESS AND PROFESSIONAL
REGULATION, 2601 BLAIR STONE RD., TALLAHASSEE, FL 32399, (850) 487-1395.
Document.24 FL Page 6 of 10
DocuSign Envelope ID:93D4BC30-6A6B-4B4C-A5B5-58026D55458A THIS IS A COPY
The Authoritative Copy of this record is held at na2.docusign.net
momentum
SOLAR
Acceptance and Authorization: By signing below, you authorize us to perform the installation. Except
as set forth in this agreement, you agree there are no oral or written representations or inducements,
expressed or implied, any way conditioning this agreement, and we expressly disclaim their existence. By
signing this agreement, you acknowledge that you have read and understand this agreement or have had
a competent legal representative explain its terms, and hereby accept this agreement in its entirety. You
further acknowledge receiving a complete copy of this agreement.
You, the buyer, may cancel this transaction at any time prior to midnight of the third business
day after the date of this transaction. See the attached notice of cancellation form for an
explanation of this right.
Customer Signature: Pro Custom Solar LLC
d/b/a Momentum Solar:
IL
DocuSigneed by:
f �a 01/19/22 SLWA (LL 01/19/2022
Tony Pereira Date Sung Lee Date
Chief Financial Officer
1
Document.24 FL Page 7 of 10
DocuSign Envelope ID:93D4BC30-6A6B-4B4C-A5B5-58026D55458A THIS IS A COPY
The Authoritative Copy of this record is held at na2.docusign.net
momentum
SOLAR
Notice of Cancellation
Date of Transaction: 01/19/22
You may CANCEL this transaction, without any Penalty or Obligation, within THREE BUSINESS DAYS
from the above date.
If you cancel, any property traded in, any payments made by you under the contract or sale, and any
negotiable instrument executed by you will be returned within TEN BUSINESS DAYS following receipt
by the seller of your cancellation notice, and any security interest arising out of the transaction will be
cancelled.
If you cancel, you must make available to the seller at your residence, in substantially as good condition
as when received, any goods delivered to you under this contract or sale, or you may, if you wisil
comply with the instructions of the seller regarding the return shipment of the goods at the se I
expense and risk.
If you do make the goods available to the seller and the seller does not ck them up within 20 days of
the date of your Notice of Cancellation, you may retain or dispose of the goods without any further
obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the
seller and fail to do so, then you remain liable for performance of all obligations under the contract.
To cancel this transaction, mail or deliver a signed and dated copy of this Cancellation Notice or any
other written notice, or send an email, to Momentum Solar, 3096B Hamilton BLV, S. Plainfield, NJ,
07080 (1-888-666-3688), Cancel Request@MomentumSolar.coml NOT LATER THAN MIDNIGHT OF
THE THIRD BUSINESS DAY AFTER 01/19/22
1 HEREBY CANCEL THIS TRANSACTION.
Date:
Buyer's Signature:
Document.24 FL Page 8 of 10
DocuSign Envelope ID:93D4BC30-6A6B-4B4C-A5B5-58026D55458A THIS IS A COPY
The Authoritative Copy of this record is held at na2.docusign.net
momentum
SOLAR
Notice of Cancellation
Date of Transaction: 01/19/22
You may CANCEL this transaction, without any Penalty or Obligation, within THREE BUSINESS DAYS
from the above date.
If you cancel, any property traded in, any payments made by you under the contract or sale, and any
negotiable instrument executed by you will be returned within TEN BUSINESS DAYS following receipt
by the seller of your cancellation notice, and any security interest arising out of the transaction will be
cancelled.
If you cancel, you must make available to the seller at your residence, in substantially as good condition
as when received, any goods delivered to you under this contract or sale, or you may, if you wistj
comply with the instructions of the seller regarding the return shipment of the goods at the seller
expense and risk. a
If you do make the goods available to the seller and the seller does not�k them up within 20 days of
the date of your Notice of Cancellation, you may retain or dispose of the goods without any further
obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the
seller and fail to do so, then you remain liable for performance of all obligations under the contract.
To cancel this transaction, mail or deliver a signed and dated copy of this Cancellation Notice or any
other written notice, or send an email, to Momentum Solar, 3096B Hamilton BLV, S. Plainfield, NJ,
07080 (1-888-666-3688), Cancel Request@MomentumSolar.com-, NOT LATER THAN MIDNIGHT OF
THE THIRD BUSINESS DAY AFTER 01/19/22
1 HEREBY CANCEL THIS TRANSACTION.
Date:
Buyer's Signature:
Document.24 FL Page 9 of 10
DocuSign Envelope ID:93D4BC30-6A6B-4B4C-A5B5-58026D55458A THIS IS A COPY
The Authoritative Copy of this record is held at na2.docusign.net
momentum
SOLAR
Attachment 1
Mandatory Liability Insurance Obligation
The Florida Public Service Commission, pursuant to Section 120.54, Florida Statutes, has adopted Rule 25-6.065,
Florida Administrative Code, relating to interconnection and net metering of customer-owned renewable
generation. Section (5)(e) requires that the owner of a Tier 2 renewable generation system have general liability
insurance for personal and property damage of$1 million. A Tier 2 renewable generation system is one that is
11.76 kW(dc) or 10.0 kW(ac) or larger.
Your local utility has interpreted this to mean that, in order to interconnect your solar generation system to the local
utility grid (and for it to function and provide you with the electricity it generates), you will ha a to provide proof
that you have$1 million of general liability insurance as part of the application for Interco ection with their
system.
By initialing here, you acknowledge that you understand the terms of this ' ra raph n e im ations
if you fail to provide and maintain proof of this insurance:
Customer Initials:
Alternatively, an owner of a Tier 2 renewable generation system ay self-insure-this $1 million if it can
demonstrate to the utility that the owner has sufficient financial means to cover a potential $1 million obligation.
As part of the interconnection process, your local utility will let you know what information it needs from you to
make this determination and the timeline for such determination.
Failure to provide proof of suc�surance t to obtali�approval from the interconnecting utility to allow you to
self-insure will result in a deniall�f your request to interconnect your system or, if interconnected, the termination
of such interconnection. Without this interconnection,your system will not operate,you will not be able to
offset any electricity used in your home and you will not be able to obtain any benefits of net metering any
extra ener ourlsystem produces.
By initialin-g hire, you acknowledge that you understand the terms of this paragraph and the implications
if you fail to provide either the proof of insurance or the local utility's approval to self-insure instead of
providing this insurance:
DS
Customer Initials:
Document.24 FL Page 10 of 10