HomeMy WebLinkAboutBuilder's At Risk Permit Acknoledgment1
This instrument prepared by (and return to):
St. Lucie County
2300 Virginia Ave.
Fort Pierce, FL 34982 -5632
(772) 462- 1 100
Builder's At Risk Permit Acknowledgement
Contractor/Qualifier: D. R. Horton Inc
(Printed name of company or person applying for permit, "Applicant")
321-733-7972
Phone #
Legal Description:
Lot Block
Subdivision Name: Creekside
Street Address: 3108 Yellowstone CIR
Melboumeoermitting(o�Orhorton com
Email Address
Plat Name
Page
WHEREAS, the above referenced plat has been recorded in Plat Book
of the official records of St. Lucie County; and
WHEREAS, Applicant has requested a building permit for the above referenced
property; and
WHEREAS, certain infrastructure improvements ("Improvements") necessary to
serve the above referenced property have not been completed; and
WHEREAS, access to the subject lot may be restricted until the Improvements are
completed, including access by emergency vehicles; and
WHEREAS, the applicant has installed BMPs to maintain positive drainage and
meet NPDES requirements; and
WHEREAS, the applicant has installed a functioning master lake system that detains
'stormwater on site and controls the discharge; and
WHEREAS, the applicant has installed the gravity collection system, including
main lines, manholes and services necessary to serve the above referenced property; and
WHEREAS, the applicant has installed the water distribution system, including
main lines, valves, hydrants and services necessary to serve the above referenced
property; and
Page 1 of 3
WHEREAS, Applicant acknowledges that Applicant's negligence, or negligence on
the part of any of the Applicant' s sub -contractors, to exercise every reasonable precaution
Possible to protect the integrity of Improvements will cause Applicant's current and future
At Risk Permit privileges to be revoked; and
WHEREAS, a nonrefundable processing fee is submitted herewith; and
WHEREAS, infrastructure bonds were previously submitted and accepted by the
County;
NOW, THEREFORE, Applicant hereby acknowledges:
1. The above recitals are true and correct and are incorporated he by this
reference.
2• Applicant hereby agrees to hold County, its agents, employees and affiliates,
harmless from any and all manner of actions, causes of action, suits, damages,
judgments, executions, claims for personal injury or property damage, demands
or losses of any kind whatsoever, in law or in equity, which may arise as a result
of Applicant's commencement of construction prior to the completion of the
Improvements, including, but not limited to, losses from the loss of
workmanship and materials due to fire or other disasters whether manmade or
natural, and/or losses due to delays in obtaining a final certificate of occupancy
resulting in part or all from the failure to complete some or all of the
Improvements.
3• Applicant agrees to strictly follow the requirements set forth in the County's
Pilot Program Builder's At Risk Permit Policy dated September 21, 2016.
4. Applicant acknowledges that a water meter will not be installed for the subject
property until the St. Lucie County Utility Department (SLCUD) has issued a
letter of acceptance.
5. Applicant shall be responsible for the cost of any damages to County facilities
occurring as a result of the issuance of building permits pursuant to this
Acknowledgement for one year after the issuance of a Certificate of Occupancy
(CO). The g911j14 will submit an itemized statement to the Applicant
immediately after the damages are recognized.
6• Applicant agrees to remove any subcontractor or contractor on the project who
is determined by the County to be negligent in regards to the Improvements on site
and who continues to damage or destroy the Improvements which jeopardize the
health, safety and welfare of the citizens.
7. Applicant agrees to immediately cease construction of the home and
construction -related activities upon the County, as specified by Code, provides
a notice to cease work.
8• Applicant shall not transfer ownership of the home or unit until a CO is issued.
Page 2 of 3
Q. '
9. Applicant shall record this "Builder's At Risk Permit Acknowledgement" form
in the Public Records of St. Lucie County, Florida, at their own expense and
provide a copy of the same to the County.
IN WITNESS WHEREOF, Applicant has executed this Acknowledgment on the date
indicated below.
�Vd 11N kin
For Applicant By: (printed name)
STATE OF FLORIDA
Signature
County of. St -Lucie County
The foregoing instrument was acknowledged before me this
?���� day of �t-� , 20_.
of
Date
Said person c� impersonally known to me, or (produced other identification, to wit:
Notary Public
�x ♦ Notary Public State of Florida
IN Sandra Leone
My com iss{on GG 020251
pia Nd Expires 08110=20
For County Use:
Sa;idl-a Leon
Print Name
Public Works Department
11 Fee Submitted Request Approved 0 Request Denied
Comments:
Printed Name Signature Date
Utility Systems Department
Fee Submitted 0 Request Approved Request Denied
Comments:
Printed Name Signature Date
Page 3 of 3